4520. Contractors Claim for Changed or Extra Work | Pdf Doc Docx | Jury Instructions

 California Jury Instructions /  45 Construction Law /
4520. Contractors Claim for Changed or Extra Work | Pdf Doc Docx | Jury Instructions

4520. Contractors Claim for Changed or Extra Work

This is a California Jury Instructions form that can be used for Construction Law.

Alternate TextLast updated: 1/21/2016

Included Formats to Download
$ 13.99

Description

4520. Contractor's Claim for Changed or Extra Work Instruction No 1 Request by Plaintiff Given as Proposed Refused Withdrawn Request by Defendant Given as Modified Requested by Given on Court's Motion Judge Instruction No 1 [Name of plaintiff] claims that [name of defendant] required [him/her/it] to perform [changed/ [or] extra] work beyond that required by the contract. [Name of plaintiff] claims that [[he/she/it] should be compensated/ [and] should have been given a time extension] [under the contract]. To succeed on this claim, [name of plaintiff] must prove all of the following: 1. 2. 3. 4. That the [changed/ [or] extra] work was [not included in/ [or] in addition to that required under] the original contract; That [name of defendant] directed [name of plaintiff] to perform the [changed/ [or] extra] work; That [name of plaintiff] performed the [changed/ [or] extra] work; That [name of plaintiff] was harmed because [name of defendant] required the [changed/ [or] extra] work. ________________________________________________________________________________ New December 2010

Our Products